Direct cost incurred during delay period x home office overhead home office overhead owed estimated or known hooh portion of bid markup.
What is home office overhead. Unabsorbed home office overhead is also a well known but not well understood delay damage and like extended field overhead is only caused by a critical project delay. Overhead refers to all non labor expenses required to operate your business these expenses are either fixed or variable. Former calculating your office over head right now. The other kind of overhead is home office overhead.
Let s break the process down. These are indirect costs because. These costs by definition are not attributable to any specific project. This formula has also referred to as the direct cost allocation method.
No matter what your sales volume is fixed costs must be. Existing ambient lighting is not designed for functional lighting in the home office and it s necessary to add additional sources. As we could see later in this article case laws continue to refine and define head office overheads until today. Home office overhead costs are overhead costs incurred by the contractor that are not associated with a particular project but really are necessary to support the contractor s operations as a whole.
Again the best example of this may be the contractor s home. The figure on page 66 shows a basic overhead cal culations sheet one you can use as a model to devise your own office over head document. Many home offices have ambient lighting that includes overhead or recessed lights but it s a mistake to think that those will suffice. It s a simple example the numbers are fictitious and you will almost certainly find yourself adjusting.
This formula has also been called the direct cost allocation method the difference between the two methodologies is simply that the eichleay formula develops a daily overhead rate which is then multiplied by the total number of owner caused delay days while the manshul formula uses the as bid home office overhead rate multiplied by the actual cost of work performed during the delay. Home office overhead costs are costs that are incurred to support the work but are not directly chargeable to a specific project. Home office overhead is a part of a contractor s indirect costs on a construction project. It is a creature of the courts in the state of new york.
The calculation of head office overheads or extended home office overheads have been puzzling many in the construction industry for a number of years.